1. Introduction and Acceptance
These Terms and Conditions (“Terms“) govern your access to and use of the website located at www.hatchrenovations.com.au (“Website“) and any services, consultations, or renovation work provided by:
Business Name: Hatch Renovations Pty Ltd
ABN: 43 650 724 815
Address: Unit 6, 22 King Edward Road, Osborne Park WA 6017
Email: info@hatchrenovations.com.au
Phone: 0422 524 363
Website: www.hatchrenovations.com.au
By accessing this Website or engaging our services, you confirm that you have read, understood, and agree to be bound by these Terms and our Privacy Policy. If you do not agree, you must not use this Website or engage our services.
These Terms apply to all visitors, users, enquirers, and clients of Hatch Renovations Pty Ltd (“we,“ “us,“ “our“).
Hatch Renovations Pty Ltd provides residential and commercial renovation services including but not limited to:
The specific scope of any engagement is defined in a written quote or formal contract between Hatch Renovations Pty Ltd and the client. These Terms apply alongside any such quote or contract and, where there is any conflict, the written contract will prevail.
All quotes provided are valid for 30 days from the date of issue unless otherwise stated. A quote is not a binding contract until both parties have signed a formal agreement.
Estimates are indicative only. Final pricing may vary based on site conditions, scope changes, or unforeseen works discovered during the project. Any variations will be communicated in writing and require written approval before proceeding.
Work commences only upon receipt of a signed contract and any required deposit. Commencement dates are estimates and subject to material availability, weather, and other factors outside our reasonable control. We will communicate any material changes to the schedule as soon as practicable.
This Website is provided for the purpose of informing prospective and existing clients about our services, facilitating enquiries, and enabling appointment bookings. You agree to use this Website only for lawful purposes and in a manner that does not infringe the rights of others.
You must not:
We do not guarantee that the Website will be continuously available or free from errors. We reserve the right to modify, suspend, or discontinue any part of the Website at any time without notice.
All content on this Website, including but not limited to text, images, photography, project portfolios, graphics, logos, and design elements, is the property of Hatch Renovations Pty Ltd or its licensors and is protected by Australian copyright law.
We grant you a limited, non-exclusive, non-transferable licence to access and view Website content for personal, non-commercial purposes only. This licence does not include the right to:
This Website and all of its content is expressly excluded from use as training data, fine-tuning data, evaluation data, or any other input for large language models (LLMs), generative AI systems, machine learning models, or automated data harvesting tools. This restriction applies to all parties, including AI developers, research organisations, and commercial operators.
Any use of this Website’s content for AI or machine learning purposes without our prior written consent constitutes a breach of these Terms and an infringement of our intellectual property rights. We reserve the right to seek injunctive relief and damages in such cases.
All prices quoted are in Australian Dollars (AUD) and, unless otherwise stated, are inclusive of GST. Pricing is based on information available at the time of quoting. We reserve the right to adjust pricing if the original scope of work changes materially.
A deposit is required to secure your project booking. The deposit amount and payment schedule will be specified in the project contract. Typical payment milestones include:
Payments are due within 7 days of invoice unless otherwise agreed in writing. Overdue amounts may attract interest at the rate of 10% per annum calculated daily, and we reserve the right to suspend work until outstanding payments are received.
Any change to the agreed scope of works constitutes a variation. Variations must be agreed in writing before any additional work is carried out. We will not be liable for delays caused by variations that have not been approved in writing.
Where applicable, GST is charged in accordance with the A New Tax System (Goods and Services Tax) Act 1999. Tax invoices will be provided upon request.
Our services come with guarantees that cannot be excluded under the Australian Consumer Law (ACL), Schedule 2 of the Competition and Consumer Act 2010 (Cth). Nothing in these Terms is intended to exclude, restrict, or modify any right or remedy you may have under the ACL.
For services supplied to consumers, we guarantee that our services will be:
To the maximum extent permitted by law, our liability for any claim arising out of or in connection with the Website or our services is limited to:
We are not liable for any indirect, incidental, consequential, special, or punitive damages, including loss of profit, loss of data, or loss of goodwill, arising from your use of the Website or our services, except to the extent such liability cannot be excluded under the ACL.
We will rectify any defective workmanship identified within the defects liability period specified in your contract (typically 12 months from practical completion), provided:
We will make reasonable efforts to complete works within agreed timeframes. However, we are not liable for delays caused by events beyond our reasonable control, including:
Where a delay is anticipated, we will notify you as soon as reasonably practicable and provide a revised timeline.
To enable us to perform our services effectively, you agree to:
We are not liable for delays, defects, or additional costs caused by your failure to meet these responsibilities.
We collect, use, and store personal information in accordance with our Privacy Policy, available at www.hatchrenovations.com.au. By using this Website or engaging our services, you consent to the collection and use of your personal information as described in that policy.
Our Privacy Policy forms part of these Terms and is incorporated by reference.
This Website may contain links to third-party websites, including platforms such as Google, Meta, or social media channels. These links are provided for convenience only. We do not control, endorse, or accept responsibility for the content or privacy practices of any third-party website.
Your use of any third-party website is subject to that website’s own terms and conditions and privacy policy.
Our Website uses Google Analytics and Meta Pixel to collect anonymised data about how visitors use our site. This information helps us improve our Website and better understand our audience.
By using this Website, you consent to the use of these technologies as described in our Privacy Policy. You may opt out of analytics tracking at any time using your browser settings or the relevant opt-out tools provided by Google and Meta.
The information on this Website is provided in good faith and is intended as general information only. It does not constitute professional advice. We make no warranties, express or implied, as to the accuracy, completeness, or suitability of any information on this Website.
Photographs and project portfolios on this Website represent past work and are not a guarantee of specific outcomes. Renovation results vary based on site conditions, materials, and scope of works.
We endeavour to ensure that all information on the Website is accurate and current. However, we do not warrant that the Website is free from errors or omissions and reserve the right to correct any errors at any time.
You agree to indemnify, defend, and hold harmless Hatch Renovations Pty Ltd and its directors, employees, contractors, and agents from any claims, losses, damages, costs, or expenses (including reasonable legal fees) arising from:
You may cancel a project engagement by providing written notice to us. Cancellation terms, including any applicable cancellation fees, will be set out in the project contract. Where no specific cancellation terms are agreed, reasonable costs incurred up to the point of cancellation are payable.
We reserve the right to suspend or terminate a project or your access to this Website if:
We will provide reasonable notice wherever possible before suspending or terminating a project.
In the event of a dispute arising from these Terms or our services, both parties agree to:
For residential building disputes in Western Australia, the relevant body is the State Administrative Tribunal (SAT) or the Department of Energy, Mines, Industry Regulation and Safety (DEMIRS) Building Commission.
These Terms are governed by the laws of Western Australia and the Commonwealth of Australia. You agree to submit to the non-exclusive jurisdiction of the courts of Western Australia for any dispute arising under these Terms.
We reserve the right to update or amend these Terms at any time. Changes will be posted on this Website with the updated effective date. Your continued use of this Website or engagement of our services after any changes constitutes your acceptance of the updated Terms.
We encourage you to review these Terms periodically. The current version will always be available at www.hatchrenovations.com.au.
For any questions, concerns, or notices regarding these Terms, please contact us:
Hatch Renovations Pty Ltd
Address: Unit 6, 22 King Edward Road, Osborne Park WA 6017
Email: info@hatchrenovations.com.au
Phone: 0422 524 363
Website: www.hatchrenovations.com.au
Version Date Changes
1.0 12 May 2026 Initial publication
Next Review Date: May 2027
End of Terms and Conditions
